Home Case Index All Cases Companies Law Companies Law + SC Companies Law - 2007 (1) TMI SC This
Forgot password New User/ Regiser ⇒ Register to get Live Demo
2007 (1) TMI 498 - SC - Companies LawWhether Jala Nigam could be allowed to raise the contention, on the facts and circumstances of this case, that Clause 29 of the Contract(Agreement) is not an arbitration clause and due to want of jurisdiction of the arbitral tribunal to adjudicate upon the claims made by the contractor (respondent no.1), Award dated 25.6.2000 published on 14.11.2000 was a nullity? Held that:- The plea of "no arbitration clause" was not raised in the written statement filed by Jala Nigam before the Arbitrator. The said plea was not advanced before the civil court in Arbitration Case No.1 of 2001. On the contrary, both the courts below on facts have found that Jala Nigam had consented to the arbitration of the disputes by the Chief Engineer. Jala Nigam had participated in the arbitration proceedings. It submitted itself to the authority of the Arbitrator. The Arbitrator has awarded Rs.42,000/- per day for the period 1.2.94 to 17.12.94 and from 1.6.95 to 31.12.95 excluding the period 18.12.94 to 31.5.95 and from 1.1.96 to 12.11.96. On this basis the idling charges awarded by the Arbitrator was arrived at Rs.1.47 crores. It is contended that the contractor has not led any evidence to show the existence of the machinery at site and, therefore, he was not entitled to idling charges. We are of the view that the Award of the Arbitrator is fair and equitable. He has excluded certain periods from calculations, as indicated above. We have examined the records. The delay took place on account of non-supply of Drawings and Designs and in the meantime the establishment of the contractor stood standstill. We suggested to the learned counsel for the respondent (contractor) for reduction of the awarded amount under this Head from Rs.1.47 crores to Rs.1 crore. Learned counsel for the respondent fairly accepted our suggestion. We suggested the aforestated figure keeping in mind the longstanding dispute between the parties. Therefore, the amount awarded under this Head shall stand reduced from Rs.1.47 crores to Rs.1 crore. Appeal stands allowed to the extent indicated above
|